Stick with it, work diligently and you'll arrive at the end. Equally if the resources are as planned but there is still delay, then this may be used by a contractor to evidence they are proceeding regularly and diligently. Voiced by: Kenichi Suzumura (drama CD), Jun Fukuyama (anime) The main character of Working! If you need to work on something more diligently, Gwinnett Yoga Center offers private instruction at the studios or in your home. Conversely, Contractors can more easily dispute the validity of the first notice and/or argue it was issued unreasonably or even vexatiously8 if the initial notice is a bare allegation. Even if it is patently obvious to the project team that the Contractor is in financial difficulties and will struggle to continue with the job, proving it to an adjudicator or to the court is not an easy task. Yes! Remote jobs for Digital Working Nomads. The brothers worked diligently to build a tree house. The priests diligently practise all the precepts of their rituale.g. Download Working Solutions and enjoy it on your iPhone, iPad, and iPod touch. If correct, then the Employer is in repudiatory breach of contract and the Contractor is entitled to claim damages. Segnala un errore o suggerisci miglioramenti. Video evidence should be obtained over a period of time and should ensure wide coverage of the site. No problem. The popular games are easy to find, but it's those rare games that you need to diligently search for. Learn more. The series was created and executive produced by Michael Davidoff and Bill Rosenthal. 1. Type Greek characters with a virtual keyboard. What is clear then is that delay on its own is not a failure to proceed regularly and diligently. Required fields are marked *. He completely rejected the contractors argument that the diligence obligation did not require it to achieve a completion date which was impossible to achieve but that, at any given moment, the obligation of due diligence should be assessed with regard to what was feasible at that time. Live-line working, the maintenance of electrical equipment while it is energised. The word usage examples above have been gathered from various sources to reflect current and historical usage. If so, are you still within the 21-day period following that? The brothers worked diligently to build a tree house. He diligently cultivated the rice field in the rural areas for five years. WordReference English-Greek Dictionary 2023: / diligently : | | | | | | | | | | | | | | | . Most employers want to rely on their contractors experience and expertise to resource, plan and programme the works and achieve completion by the specified date. Limiting time in the sun, avoiding mid-day rays, and using sunscreen diligently will help hold back the years. I love Working Solutions. Google Translate diligently. I want to receive exclusive email updates from YourDictionary. So what evidence should be obtained? If you would like to receive a digital version of our newsletters please complete the subscription form. Their investigation has since been diligently prosecuted. This crossword clue Working diligently was discovered last seen in the October 20 2022 at the NewsDay Crossword. Thereafter he had no settled charge, but, until his death at Hartford on the 17th of February 1876, he occasionally preached and was diligently employed as an author. (. Pressing danger could only exist if Blucher had gone northwards, and northwards, therefore, in the Dyle valley, he should have diligently sought for traces of the Prussian retreat.'. His object was to make all the anatomical and physiological acquisitions of his age, even microscopical anatomy, which he diligently studied, available for use in the practice of medicine. working ngha, nh ngha, working l g: 1. relating to work: 2. having work: 3. operating: . In general terms, unless the contract expressly provides otherwise, there is no obligation on a contractor to accelerate the works when it is in culpable delay, although a contractor can always choose to do so in order to avoid the consequences of late completion. Waiting until after the first warning notice has been issued under clause 8.4.1 to start assembling the evidence to support it is far from ideal. 2023 LoveToKnow Media. "If" one thing happens, "then" another thing will happen. and In that sense it is an objective concept, though its requirements will depend in each case upon the terms of the contract in question. According to the title-page the New Testament was " translated faithfvlly into English ovt of the authentical Latin, according to the best corrected copies of the same, diligently conferred vvith the Greeke and other editions in diuers languages.. At Cambridge he applied himself diligently to the several sciences as then taught, and came to the conclusion that the methods employed and the results attained were alike erroneous. He kept on diligently collecting materials, and as he did so was constrained to modify some of the statements he had published. Study GPS reviews and comparisons diligently to ensure you are getting the right GPS for your needs. Does the Employer have the right to terminate the Contractors employment for failure to proceed regularly and diligently under a JCT standard form contract? Nine pounds for ninety pages on a film you might have trouble finding at even the most diligently cataloged video shop often seems extravagant. Privacy Policy. Virgo's partner can expect that this sign will work diligently to correctwhatever ails their relationship, not just out of love, but out of principle. Concurrent delay: the latest guidance from the courts, Delay does not of itself provide conclusive proof of a lack of due diligence, but it may suggest and evidence a lack of due diligence (, Failing to achieve the programmed productivity because of inadequate resourcing will usually evidence a failure to proceed regularly and diligently (, Where an employer is actively trying to manage and mitigate any delay caused by its contractor and requests the contractor to re-deploy resources to higher priority areas, this may jeopardise any subsequent claim that the contractor has failed adequately to resource the works. Encouraged by their success, he devoted himself diligently to this kind of composition, but refrained for a long time from either publicly reciting or publishing his verses. In that case Mr Justice Ramsey viewed a lack of productivity as being the best evidence of a failure to proceed regularly and diligently.5 However, he also noted that the failure to provide a proper programme (and one in accordance with their contractual obligations) undoubtedly resulted, in that case, in an inability to proceed continuously, industriously and efficiently with appropriate physical resources so as to progress the works towards completion.6. "diligently" Greek . How to use hardworking in a sentence. Because people are urged to wear sunscreen diligently and some people don't get outside much, it's easier now to have a vitamin D deficiency than in the past. Trying to find another word for diligently in English? If you are a lawyer or work in a legal capacity, please register for a free trial to see if Practical Laws resources are right for your business. The diligence obligation survives and instead attaches to the nearest possible approximation to proper contractual performance, namely, the contractual objective of minimising the ongoing breach. Working Solutions is the Best company to work for that I have experienced. working ( wk) n 1. the operation or mode of operation of something 2. the act or process of moulding something pliable 3. Conditional Sentences: Examples of the Different Types, What Is a Gerund? He worked diligently at original manuscript authorities at Simancas, the Record Office and Hatfield House; but he used his materials carelessly, and evidently brought to his investigation of them a mind already made up as to their significance. He kept on diligently collecting materials, and as he did so was constrained to modify some of the statements he had published. 3. File a Civil Rights Complaint. Click on the arrows to change the translation direction. The consequences of getting it wrong can be high. On a typical day, they work in semi-private or private offices, communicate with team members and other people in management, attend meetings, and conduct coaching sessions as needed. PastTenses is a database of English verbs. Because you know theyre not really scary creatures theyre just kids dressed up in costumes so they can get candy. The first notice (the default notice otherwise known as a hurry-up notice10) sets out the failure to proceed regularly and diligently, whilst the second notice (only to be issued if the same behaviour continues for 14 days from the default notice and within 21 days of that) terminates the Contractors employment under the contract. Californias online employment resource. Meanwhile, the French in Metz had been diligently at work. Here he worked diligently at practical reforms, being specially anxious to raise the standard of clerical life and work. Manca qualcosa di importante? The case of Vivergo Fuels v Redhall Engineering Solutions4 provides a useful insight into how a court is likely to evaluate whether there has been a failure to proceed regularly and diligently. Forum discussions with the word(s) 'diligently' in the title: Discussioni su 'diligently' nel forum English Only, Una o pi discussioni del forum combaciano perfettamente col termine che hai cercato, Journalists should diligently seek out subjects of news stories to give them the opportunity to respond to allegation of wrongdoing, by planning carefully and
working diligently and industriously
You must be chanute police department to post a comment.